01-25-2016 Council Packet - Laserfiche WebLink

Home Search

§ 14.3.2 The Contract Sum and Contract Time shall be adjusted for increases in the cost and time caused by suspension, delay or interruption as described in Section 14.3.1. Adjustment of the Contract Sum shall include profit. No adjustment shall be made to the extent .1 that performance is, was or would have been so suspended, delayed or interrupted by another cause for which the Contractor is responsible; or .2 that an equitable adjustment is made or denied under another provision of the Contract. § 14.4 TERMINATION BY THE OWNER FOR CONVENIENCE § 14.4.1 The Owner may, at any time, terminate the Contract for the Owner's convenience and without cause. § 14.4.2 Upon receipt of written notice from the Owner of such termination for the Owner's convenience, the- -_- Contractor shall .1 cease operations as directed by the Owner in the notice; .2 take actions necessary, or that the Owner may direct, for the protection and preservation of the Work; and .3 except for Work directed to be performed prior to the effective date of termination stated in the notice, terminate all existing subcontracts and purchase orders and enter into no further subcontracts and purchase orders. 1 I I „ F § 14.4.3 In case of such termination for the Owner's convenience, the Contractor shall be entitled to recei se payment for Work executed, and costs incurred by reason of such termination, along with reasonable overhead and profit on the Work not executed. ARTICLE 15 CLAIMS AND DISPUTES § 15.1 CLAIMS § 15.1.1 DEFINITION A Claim is a demand or assertion by one of the parties seeking, as a matter of right, payment of money, orother relief with respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question between the Owner and Contractor arising out of or relating to the Contract. The responsibility to substantiate Claims shall rest with the party making the Claim. § 15.1.2 NOTICE OF CLAIMS Claims by either the Owner or Contractor must be initiated by written notice to the other party and to the Initial,. Decision Maker with a copy sent to the Architect, if the Architect is not serving as the Initial Decision Maker. Claims by either party must be initiated within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is -later. § 15.1.3 CONTINUING CONTRACT PERFORMANCE Pending final resolution of a Claim, except as otherwise agreed in writing or as provided infSection 9.7 aid Article-' 14, the Contractor shall proceed diligently with performance of the Contract and the Owner) shall continue to make payments in accordance with the Contract Documents. The Architect will prepare Change Orders and issue Certificates for Payment in accordance with the decisions of the Initial Decision Maker. I § 15.1.4 CLAIMS FOR ADDITIONAL COST I' If the Contractor wishes to make a Claim for an increase in the Contract Sum, written notice as'provided herein -shall---- be given before proceeding to execute the Work. Prior notice is not required for Claims relating to an emergency endangering life or property arising under Section 10.4. -_ § 15.1.5 CLAIMS FOR ADDITIONAL TIME § 15.1.5.1 If the Contractor wishes to make a Claim for an increase in the Contract Time,writen,notice as provided herein shall be given. The Contractor's Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary. § 15.1.5.2 If adverse weather conditions are the basis for a Clain for additional time, such Glairn shall be documented by data substantiating that weather conditions were abnormal for the period ofttime, could not have been reasonably anticipated and had an adverse effect on the scheduled construction. - __ __ -_ AIA Document A201a' — 2007. Copyright O 1911, 1915, 1918, 1925, 1937, 1951, American Institute of Architects. All rights reserved. WARNING: This AIA° Treaties. Unauthorized reproduction or distribution of this AIA' Document, penalties, and will be prosecuted to the maximum extent possible under the 08/20/2009 under Order No.37269892921 which expires on 05/28/2010, and is User Notes: 1958, 1961, 1963, 1966, 1970, 1976, 1987, 1997 and 2007 by The Document is protected by U.S. Copyright Law and International or any portion of it, may result in severe civil and criminal law. This draft was produced by AIA software at 15:05:44 on not for resale. (926118731)