Agenda Packets - 2022/06/13 - Laserfiche WebLink

Home Browse Search

24. Other Tasks: Perform or provide the following other Construction Phase tasks or deliverables: N/A 25. Final Notice of Acceptability of the Work: Conduct a final visit to the Project to determine if the Work is complete and acceptable so that Engineer may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, Engineer shall also provide a notice to Owner and Contractor in the form attached hereto as Exhibit E ("Notice of Acceptability of Work") that the Work is acceptable (subject to the provisions of the Notice and Paragraph A1.05.A.21.b) to the best of Engineer's knowledge, information, and belief, and based on the extent of the services provided by Engineer under this Agreement. 26. Standards for Certain Construction -Phase Decisions: Engineer will render decisions regarding the requirements of the Construction Contract Documents, and judge the acceptability of the Work, pursuant to the specific procedures set forth in the Construction Contract for initial interpretations, Claims, and acceptance of the Work. In rendering such decisions and judgments, Engineer will not show partiality to Owner or Contractor, and will not be liable to Owner, Contractor, or others in connection with any proceedings, interpretations, decisions, or judgments conducted or rendered in good faith. B. Duration of Construction Phase: The Construction Phase will commence with the execution of the first Construction Contract for the Project or any part thereof and will terminate upon written recommendation by Engineer for final payment to Contractors. If the Project involves more than one prime contract as indicated in Paragraph A1.03.D, then Construction Phase services may be rendered at different times in respect to the separate contracts. Subject to the provisions of Article 3, Engineer shall be entitled to an equitable increase in compensation if Construction Phase services (including RPR services, if any) are required after the original date for completion and readiness for final payment of Contractor as set forth in the Construction Contract. Agreement Summary: Original Agreement amount: $477,500.00 Net change for prior amendments: $682,900.00 This Amendment amount: $7,500.00 Adjusted Agreement amount: $1,167,400.00 The foregoing Agreement Summary is for reference only and does not alter the terms of the Agreement, including those set forth in Exhibit C. Owner and Engineer hereby agree to modify the above -referenced Agreement as set forth in this Amendment. All provisions of the Agreement not modified by this or previous amendments remain in effect. Amendment No. 3 to Agreement Between Owner and Engineer for Professional Services Page 6