CC PACKET 06082021 - Laserfiche WebLink

Home Browse Search

Exhibit A – General Contract Provisions 11.01.16.MN Page 1 WSB & ASSOCIATES, INC. EXHIBIT A GENERAL CONTRACT PROVISIONS ARTICLE 1 – PERFORMANCE OF THE WORK Consultant shall perform the services under this Agreement in accordance with the care and skill ordinarily exercised by members of Consultant’s profession practicing under similar circumstances at the same time and in the same locality. Consultant makes no warranties, express or implied, under this Agreement or otherwise, in connection with its services. ARTICLE 2 – ADDITIONAL SERVICES If the Client requests that the Consultant perform any services which are beyond the scope as set forth in the Agreement, or if changed or unforeseen conditions require the Consultant to perform services outside of the original scope, then, Consultant shall promptly notify the Client of cause and nature of the additional services required. Upon notification, Consultant shall be entitled to an equitable adjustment in both compensation and time to perform. ARTICLE 3 – SCHEDULE Unless specific periods of time or dates for providing services are specified in a separate Exhibit, Consultant’s obligation to render services hereunder will be for a period which may reasonably be required for the completion of said services. The Client agrees that Consultant is not responsible for damages arising directly or indirectly from any delays for causes beyond Consultant’s control. For purposes of this Agreement, such causes include, but are not limited to, strikes or other labor disputes; severe weather disruptions, or other natural disasters or acts of God; fires, riots, war or other emergencies; any action or failure to act in a timely manner by any government agency; actions or failure to act by the Client or the Client’s contractor or consultants; or discovery of any hazardous substance or differing site conditions. If the delays outside of Consultant’s control increase the cost or the time required by Consultant to perform its services in accordance with professional skill and care, then Consultant shall be entitled to a reasonable adjustment in schedule and compensation. ARTICLE 4 – CONSTRUCTION OBSERVATION If requested by Client, Consultant shall visit the project during construction to become familiar with the progress and quality of the contractors’ work and to determine if the work is proceeding, in general, in accordance with plans, specifications or other contract documents prepared by Consultant for the Client. The Client has not retained the Consultant to make detailed inspections or to provide exhaustive or continuous project review and observation services. Consultant neither guarantees the performance of any Contractor retained by Client nor assumes responsibility for any Contractor’s failure to furnish and perform the work in accordance with the construction documents. Client acknowledges Consultant will not direct, supervise or control the work of contractors or their subcontractors, nor shall Consultant have authority over or responsibility for the contractors’ means, methods, or procedures of construction. Consultant’s services do not include review or evaluation of the Client’s, contractor’s or subcontractor’s safety measures, or job site safety. Job Site Safety shall be the sole responsibility of the contractor who is performing the work. For Client-observed projects, the Consultant shall be entitled to rely upon and accept representations of the Client’s observer. If the Client desires more extensive project observation or full-time project representation, the Client shall request such services be provided by the Consultant as an Additional Service. Consultant and Client shall then enter into a Supplemental Agreement detailing the terms and conditions of the requested project observation. ARTICLE 5 – OPINIONS OF PROBABLE COST Opinions, if any, of probable cost, construction cost, financial evaluations, feasibility studies, economic analyses of alternate solutions and utilitarian considerations of operations and maintenance costs, collectively referred to as “Cost Estimates,” provided for are made or to be made on the basis of the Consultant's experience and qualifications and represent the Consultant's best judgment as an 16